Rydych yn gweld hysbysiad sydd wedi dod i ben.

Cynnwys

Crynodeb

OCID:: ocds-kuma6s-110791
Cyhoeddwyd gan:: Denbighshire Leisure Ltd
ID Awudurdod:: AA79520
Dyddiad cyhoeddi:: 13 Gorffennaf 2021
Dyddiad Cau:: 12 Awst 2021
Math o hysbysiad:: SF02 Hysbysiad Contract
Mae ganddo ddogfennau:: Yndi
Wedi SPD:: Nac Ydi
Mae ganddo gynllun lleihau carbon:: AMH

Crynodeb

Denbighshire Leisure Limited (DLL) are again excited to be engaging with the market with this opportunity. This is an opportunity for a potential development partner to work with Denbighshire Leisure Limited in elevating this next iteration of the Framework to even greater heights than the previous two iterations. It is hoped this opportunity will generate interest within the Market as it is an exciting opportunity. Please also note that DLL are looking for one partner to deliver or manage the delivery of all aspects of the Framework, they are not seeking expressions of interest from organisations who can only deliver one aspect of the services e.g. design only, construct only, finance only etc. This PIN notice is being released to give potential bidders an opportunity to express initial interest in the Framework. It is to provide early engagement with the market and not designed as part of the overarching procurement strategy. All documents relating to the procurement will be issued with the Contract Notice. CPV: 45212000, 45211350, 66120000, 37480000, 45212000, 45212100, 45212110, 66000000, 66122000, 71200000, 79340000, 92610000, 92620000, 30100000, 30200000, 37400000, 37410000, 37420000, 37430000, 37440000, 37460000, 37470000, 45112711, 45212140, 45212150, 45212172, 45212180, 45212210, 37416000, 45212211, 45212212, 45212213, 45212220, 45212221, 45212222, 45212224, 45212225, 45212230, 45212300, 45212320, 45212321, 45212322, 45212330, 45212331, 45212400, 45212410, 45212420, 45212421, 45212422, 45212423, 45212500, 45212600, 48100000, 51100000, 71240000, 71241000, 71250000, 71420000, 73000000, 79341000, 79342000, 79342320, 80511000, 79410000.

Testun llawn y rhybydd

Hysbysiad contract

Adran I: Endid contractio

I.1) Enw a chyfeiriad

Denbighshire Leisure Ltd

8-11 Trem-y-Dyffryn, Colomendy Industrial Estate

Denbigh

LL165TX

Person cyswllt: Andy Moreland

Ffôn: +44 1824706724

E-bost: andy.moreland@denbighshireleisure.co.uk

NUTS: UK

Cyfeiriad(au) rhyngrwyd

Prif gyfeiriad: www.denbighshireleisure.co.uk

Cyfeiriad proffil y prynwr: https://www.sell2wales.gov.wales/search/Search_AuthProfile.aspx?ID=AA79520

I.2) Caffael ar y cyd

Caiff y contract ei ddyfarnu gan gorff prynu canolog

I.3) Cyfathrebu

Mae'r dogfennau caffael ar gael ar gyfer mynediad uniongyrchol anghyfyngedig a llawn, yn rhad ac am ddim ar:

www.sell2wales.gov.wales

Gellir cael gwybodaeth ychwanegol o'r cyfeiriad uchod

Rhaid anfon tendrau neu geisiadau i gymryd rhan yn electronig at:

www.sell2wales.gov.wales

I.4) Y math o awdurdod contractio

Corff a lywodraethir gan gyfraith gyhoeddus

I.5) Prif weithgaredd

Hamdden, diwylliant a chrefydd

Adran II: Gwrthrych

II.1) Cwmpas y caffaeliad

II.1.1) Teitl

Leisure Development Partner for the UK Leisure Framework 2022-2026

II.1.2) Prif god CPV

45212000

II.1.3) Y math o gontract

Gwaith

II.1.4) Disgrifiad byr

Please also note that DLL are looking for one partner to deliver or manage the delivery of all aspects of the Framework, they are not seeking expressions of interest from organisations who can only deliver one aspect of the services e.g. design only, construct only, finance only etc.

This PIN notice is being released to give potential bidders an opportunity to express initial interest in the Framework. It is to provide early engagement with the market and not designed as part of the overarching procurement strategy. All documents relating to the procurement will be issued with the Contract Notice.

II.1.5) Cyfanswm gwerth amcangyfrifedig

Gwerth heb gynnwys TAW: 2 000 000 000.00 GBP

II.1.6) Gwybodaeth am lotiau

Mae’r contract hwn wedi’i rannu’n lotiau: Na

II.2) Disgrifiad

II.2.2) Cod(au) CPV ychwanegol

45211350

66120000

37480000

45212000

45212100

45212110

66000000

66122000

71200000

79340000

92610000

92620000

30100000

30200000

37400000

37410000

37420000

37430000

37440000

37460000

37470000

45112711

45212140

45212150

45212172

45212180

45212210

37416000

45212211

45212212

45212213

45212220

45212221

45212222

45212224

45212225

45212230

45212300

45212320

45212321

45212322

45212330

45212331

45212400

45212410

45212420

45212421

45212422

45212423

45212500

45212600

48100000

51100000

71240000

71241000

71250000

71420000

73000000

79341000

79342000

79342320

80511000

79410000

II.2.3) Man cyflawni

Cod NUTS:

UKL13

UKN

UKC

UKD

UKE

UKF

UKG

UKH

UKI

UKJ

UKK

UKL

UKM

II.2.4) Disgrifiad o’r caffaeliad

DLL is renewing its UK Leisure Framework and seeking a Single Delivery Partner or well managed consortia who are prepared to establish a JV or other entity as a single point of contact to Manage and deliver the Framework. The appointed developer will be a leisure led specialist who has a successful and demonstrable track record of delivery of Leisure, Recreational, Multi-Use Leisure, Hotel, and Café, Bar, Theatre, Spa and Wellbeing focused centers. The scope of services deliverable under this framework are:

Concept to cost certainty for client’s calling off from the Framework

Feasibility and Business Planning

Supply chain leverage

Speed of Delivery

Project Management

Operations and Marketing Support

Risk Transfer

Track record of Successful delivery

Reduced tendering costs

The Framework can provide where required as part of the project deal:

Feasibility studies and business planning

Design management

Design services

Construction

Sourcing of and provision of Private financing option

Marketing, Branding and Sales Development.

Provision of Equipment and Services such as:

Sales and marketing management to include

Impact sales teams

Marketing campaign

Brand development

Staff Training

Digital Marketing

Mystery shopping

Equipment:

Under the Framework Leisure Operators may purchase leisure equipment:

Health and Fitness Equipment

Play, Climbing, Toning Equipment

Office and Leisure furniture

Drowning detection

IT solutions

Signage

Food and Beverages.

In terms of DLL expectations from its Partner DLL is seeking:

a. To pro-actively and robustly manage the Framework delivery,

b. Marketing, Promoting and Developing the Framework, ensuring that the success of the Framework is progressive and that clear marketing strategies and objectives are agreed, delivered, and beaten.

c. Liaise with DLL on a regular basis to develop the Framework, reporting on Project Progress.

d. Pro-actively market the framework and seek development and project delivery opportunities, promoting DLL and the framework.

e. Service an income back to DLL through its framework management processes; and

f. Manage client engagement through the term of the Framework, through construction and beyond into the defect period. To act as employer in relation to any construction project on behalf of the Client and therefore managed at practical completion, and through the defects liability period and beyond to ensure the quality of the build, and framework services.

For the Project Client:

g. Providing a procurement strategy for the client project which gives the client cost certainty before they commit to proceeding with the development and enter into contract.

h. Developing client designs working as necessary with an appropriate design team;

i. Sourcing and arranging finance or funding packages as necessary for the Clients project;

j. Taking the risk of the Client Project, site investigations and surveys until such a time that the client has achieved cost certainty, and is in a position to enter into contract;

k. Project Managing the Project on behalf of the Client until final handover;

l. Act as the Employer under the build contract and take some of the risk of the Project until Practical Completion, and provide customer support to the Client even after the achievement of Practical Completion chasing rectification of defects and any other issues.

m. Support the client on the long-term strategic planning of the facility and wider leisure provision to ensure a viable and sustainable facility is developed and managed.

n. The ability to enable the client to develop a business model, giving consideration to the wider community and the provisions that are already available within the area.

o. Liaise with DLL on a regular basis to develop the Framework, report on Project Progress.

p. Pro-actively market the framework and seek development and project delivery opportunities, promoting DLL and the framework above any other.

q. Collaborate and transparently service an income back to DLL throughout its framework management processes.

II.2.5) Meini prawf dyfarnu

Maen prawf isod:

Maes prawf ansawdd: Price / Pwysoliad: 25

Maes prawf ansawdd: Quality criteria, as listed in the procurement documents / Pwysoliad: 75

Price / Pwysoliad: See documents

II.2.6) Gwerth amcangyfrifedig

Gwerth heb gynnwys TAW: 2 000 000 000.00 GBP

II.2.7) Hyd y contract, y cytundeb fframwaith neu’r system brynu ddynamig

Dechrau: 01/02/2022

Diwedd: 31/01/2026

Gall y contract hwn gael ei adnewyddu: Ydy

Disgrifiad o’r adnewyddiadau:

The Framework is to be renewed every 4 years subject to any extensions permitted and client DLL demand.

II.2.9) Gwybodaeth am y cyfyngiadau ar nifer yr ymgeiswyr a gaiff eu gwahodd

Meini prawf gwrthrychol ar gyfer dewis y nifer cyfyngedig o ymgeiswyr:

Objective criteria for choosing the limited number of candidates is as set out in the procurement documents

II.2.10) Gwybodaeth am amrywiadau

Derbynnir amrywiadau: Ydy

II.2.11) Gwybodaeth am opsiynau

Opsiynau: Ydy

Disgrifiad o’r opsiynau:

Variants will be accepted where they demonstrate additional benefit to DLL.

II.2.13) Gwybodaeth am Gronfeydd yr Undeb Ewropeaidd

Mae'r broses gaffael yn gysylltiedig â phrosiect a/neu raglen a ariennir gan gronfeydd yr Undeb Ewropeaidd: Na

II.2.14) Gwybodaeth ychwanegol

For assistance on the process on Sell2Wales, please contact -

- Help and Resources - https://www.sell2wales.gov.wales/helpandresources

- FAQ’s - https://www.sell2wales.gov.wales/sitehelp/help_faq.aspx

For further information, please contact Andy Moreland (andy.moreland@denbighshireleisure.co.uk)

Section III: Gwybodaeth gyfreithiol, economaidd, ariannol a thechnegol

III.1) Amodau ar gyfer cymryd rhan

III.1.1) Addasrwydd i ymgymryd â’r gweithgaredd proffesiynol, gan gynnwys gofynion mewn perthynas â chofrestru ar gofrestri proffesiynol neu gofrestri masnach

Rhestr a disgrifiad byr o’r amodau:

Selection Criteria as set out in the procurement documents

III.1.2) Statws economaidd ac ariannol

Meini prawf dethol fel y’u nodir yn y dogfennau caffael

III.1.3) Gallu technegol a phroffesiynol

Rhestr a disgrifiad byr o’r meini prawf dethol:

Selection criteria as stated in the procurement documents but in order for DLL to consider any tender bids the potential contractor needs to demonstrate that they have the technical ability, the track record of having delivered leisure development projects within the last 5 years as a lead development partner which consists of design, construction, sales and marketing support and, income share. The Lead development partner must demonstrate that they have actually delivered the above scope in their own right or as part of a lead consortia, and not simply a sub-contractor on similar projects.

III.2) Amodau sy’n gysylltiedig â’r contract

III.2.2) Amodau perfformiad contractau

As set out in the procurement documents.

Section IV: Gweithdrefn

IV.1) Disgrifiad

IV.1.1) Y math o weithdrefn

Deialog Gystadleuol

IV.1.3) Gwybodaeth am gytundeb fframwaith neu system brynu ddynamig

Mae'r broses gaffael yn golygu sefydlu cytundeb fframwaith gydag un gweithredwr.

Cyfiawnhau unrhyw gyfnod o gytundeb fframwaith sy'n hwy na 8 blynedd: The Framework is for an initial period of 4 years with a discretion to extend for up to a further 2 years. This is believed to be required in order to ensure that the Framework can continue to operate where there have been any complications preventing the re-marketing of the Framework in 2026.

IV.1.4) Gwybodaeth am leihau nifer yr atebion neu’r tendrwyr yn ystod negodiad neu ddeialog

Troi at weithdrefn fesul cam er mwyn mynd ati’n raddol i leihau nifer yr atebion i’w trafod neu’r tendrau i’w negodi

IV.1.8) Gwybodaeth am Gytundeb Caffael y Llywodraeth (GPA)

The procurement is covered by the Government Procurement Agreement: Ydy

IV.2) Gwybodaeth weinyddol

IV.2.1) Cyhoeddiad blaenorol mewn perthynas â’r weithdrefn hon

Rhif yr hysbysiad yn OJ S:

2021/S 000-011246

IV.2.2) Terfyn amser i dendrau neu geisiadau i gymryd rhan ddod i law

Dyddiad: 12/08/2021

Amser lleol: 12:00

IV.2.3) Dyddiad amcangyfrifedig ar gyfer anfon gwahoddiadau i dendro neu i gymryd rhan at yr ymgeiswyr a ddewiswyd

Dyddiad: 12/08/2021

IV.2.4) Ym mha iaith/ieithoedd y gellir cyflwyno tendrau neu geisiadau i gymryd rhan

IV.2.6) Yr isafswm cyfnod gofynnol i’r sawl sy’n tendro gynnal y tendr

Hyd mewn misoedd: 6 (o’r dyddiad a nodwyd i dendr ddod i law)

Section VI: Gwybodaeth ategol

VI.1) Gwybodaeth am ailddigwydd

Caffaeliad cylchol yw hwn: Ydy

Amseriad amcangyfrifedig ar gyfer cyhoeddi hysbysiadau pellach:

Further notices may be published in 2025 - 2026

VI.3) Gwybodaeth ychwanegol

Denbighshire Leisure Limited are again excited to be engaging with the market with this opportunity. This is an opportunity for a potential development partner to work with Denbighshire Leisure Limited in elevating this next iteration of the Framework to even greater heights than the previous two iterations. It is hoped this opportunity will generate interest within the Market as it is an exciting opportunity.

The previous iterations of the Framework to date have been hugely successful and past projects can be viewed on the current iterations of the Frameworks website (https://leisureframework.co.uk/case-studies/). Bidders that wish to ask any questions around potentially bidding for the Framework, or to express an interest in the Framework, should contact Andy Moreland on andy.moreland@denbighshireleisure.co.uk and detail their questions, or their experience in dealing with clients as outlined in the short description. This will enable potential bidders to determine whether they want to proceed with their bid.

NOTE: To register your interest in this notice and obtain any additional information please visit the Sell2Wales Web Site at https://www.sell2wales.gov.wales/Search/Search_Switch.aspx?ID=112303.

The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.sell2wales.gov.wales/sitehelp/help_guides.aspx.

Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.

The Contractor shall ensure that all contracts with Subcontractors and Suppliers which the Contractor intends to procure following the Award date, and which the Contractor has not, before the date of this Contract, already planned to award to a particular Subcontractor or Supplier, are advertised through the Sell2Wales portal (www.sell2wales.gov.wales) and awarded following a fair, open, transparent and competitive process proportionate to the nature and value of the contract.

Under the terms of this contract the successful supplier(s) will be required to deliver Community Benefits in support of the authority’s economic and social objectives. Accordingly, contract performance conditions may relate in particular to social and environmental considerations. The Community Benefits included in this contract are:

Under the terms of this Contract the successful candidate will be required to deliver community benefits in support of the Welsh Government’s Act of 2015

(WA Ref:112303)

The buyer considers that this contract is suitable for consortia.

VI.4) Gweithdrefnau adolygu

VI.4.1) Corff adolygu

Denbighshire Leisure Limited

8-11 Trem Y Dyffryn, Colomendy Industrial Estate

Denbigh

LL16 5TX

E-bost: andy.moreland@denbighshireleisure.co.uk

VI.4.2) Corff sy’n gyfrifol am weithdrefnau cyfryngu

The High Court of England and Wales

Cardiff

DX 99500

Cyfeiriad(au) rhyngrwyd

URL: https://www.gov.uk/government/organisations/hm-courts-and-tribunals-service/about/complaints-procedure

VI.4.3) Gweithdrefn adolygu

Gwybodaeth fanwl gywir am y terfyn(au) amser ar gyfer gweithdrefnau adolygu:

DLL will incorporate a minimum 10 calendar day standstill period at the point that an award decision is communicated to Bidders. The award decision notice will specify the criteria for the award of the contract/framework agreement, the reason for the decision, including the characteristics and relative advantages, the name and score of the successful tender; and sill specify when the standstill period is expected to end or the date before which DLL will not conclude the contract/framework agreement. If an appeal regarding the award of a contract has not been successfully resolved the Public Contracts (Amendment) Regulations 2009 provide for aggrieved parties who have been harmed or at risk of a breach of the rules to take action in the High Court (England, Wales and Northern Ireland).

Any such action must be brought promptly within 30 days.

The court may award the setting aside of the award decision or may order DLL to amend any document and may award damages. If a framework agreement has been entered into the Court may make a declaration of ineffectiveness or may order that the duration of any relevant specific contract be shortened and additionally may award damages. The time limit for seeking such a declaration is generally 30 days from notification of the award.

VI.4.4) Y gwasanaeth lle y gellir cael gwybodaeth am y weithdrefn adolygu

Denbighshire Leisure Limited

8-11 Trem Y Dyffryn, Colomendy Industrial Estate

Denbigh

LL16 5TX

E-bost: andy.moreland@denbighshireleisure.co.uk

VI.5) Dyddiad anfon yr hysbysiad hwn

13/07/2021

Codio

Categorïau nwyddau

ID	Teitl	Prif gategori
45212500	Addasu cegin neu fwyty	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212400	Adeiladau llety a bwytai	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
71241000	Astudiaeth ddichonoldeb, gwasanaeth cynghori, dadansoddi	Gwasanaethau pensaernïol, peirianneg a chynllunio
30200000	Cyfarpar a chyflenwadau cyfrifiadurol	Peiriannau, cyfarpar a chyflenwadau swyddfa a busnes, heblaw dodrefn a phecynnau meddalwedd
37430000	Cyfarpar bocsio	Nwyddau a chyfarpar chwaraeon
37420000	Cyfarpar campfa	Nwyddau a chyfarpar chwaraeon
37410000	Cyfarpar chwaraeon awyr agored	Nwyddau a chyfarpar chwaraeon
37440000	Cyfarpar ffitrwydd	Nwyddau a chyfarpar chwaraeon
37470000	Cyfarpar golff a bowlio	Nwyddau a chyfarpar chwaraeon
37416000	Cyfarpar hamdden	Cyfarpar chwaraeon awyr agored
37460000	Gemau targed a gemau bwrdd a chyfarpar cysylltiedig	Nwyddau a chyfarpar chwaraeon
45212230	Gosod ystafelloedd newid	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212211	Gwaith adeiladau lloriau rhew	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45211350	Gwaith adeiladu adeiladau amlswyddogaethol	Gwaith adeiladu ar gyfer adeiladau aml-annedd a thai unigol
45212300	Gwaith adeiladu ar gyfer adeiladau celfyddydol a diwylliannol	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212000	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai	Gwaith adeiladu adeiladau
45212320	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â pherfformiadau artistig	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212410	Gwaith adeiladu ar gyfer adeiladau tw llety	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212420	Gwaith adeiladu ar gyfer bwytai a chyfleusterau tebyg	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212212	Gwaith adeiladu ar gyfer pwll nofio	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212321	Gwaith adeiladu awditoria	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212421	Gwaith adeiladu bwytai	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212423	Gwaith adeiladu caffeterias	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212222	Gwaith adeiladu campfeydd	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212172	Gwaith adeiladu canolfannau hamdden	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212110	Gwaith adeiladu canolfannau hamdden	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212220	Gwaith adeiladu cyfleusterau chwaraeon amlbwrpas	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212210	Gwaith adeiladu cyfleusterau chwaraeon un diben	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212100	Gwaith adeiladu cyfleusterau hamdden	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212422	Gwaith adeiladu ffreuturau	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212330	Gwaith adeiladu llyfrgelloedd	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212331	Gwaith adeiladu llyfrgelloedd amlgyfrwng	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212225	Gwaith adeiladu neuaddau chwaraeon	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212600	Gwaith adeiladu pafiliynau	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212150	Gwaith adeiladu sinemâu	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212224	Gwaith adeiladu stadia	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212180	Gwaith adeiladu swyddfeydd tocynnau	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212221	Gwaith adeiladu sy’n gysylltiedig â strwythurau ar gyfer maes chwaraeon	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212322	Gwaith adeiladu theatrau	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45212213	Gwaith gwneud marciau ar gyfer chwaraeon	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai
45112711	Gwaith tirlunio ar gyfer parciau	Gwaith cloddio a symud pridd
66000000	Gwasanaethau ariannol ac yswiriant	Cyllid a Gwasanaethau Cysylltiedig
66120000	Gwasanaethau bancio buddsoddi a gwasanaethau cysylltiedig	Gwasanaethau bancio a buddsoddi
66122000	Gwasanaethau cyllid corfforaethol a chyfalaf menter	Gwasanaethau bancio buddsoddi a gwasanaethau cysylltiedig
79342320	Gwasanaethau gofal cwsmeriaid	Gwasanaethau marchnata
51100000	Gwasanaethau gosod cyfarpar trydanol a mecanyddol	Gwasanaethau gosod (heblaw meddalwedd)
92610000	Gwasanaethau gweithredu cyfleusterau chwaraeon	Gwasanaethau hela
80511000	Gwasanaethau hyfforddi staff	Gwasanaethau cludo teithwyr ar ffyrdd at ddibenion arbennig
79341000	Gwasanaethau hysbysebu	Gwasanaethau hysbysebu a marchnata
79340000	Gwasanaethau hysbysebu a marchnata	Ymchwil marchnad ac ymchwil economaidd; arolygon barn ac ystadegau
79342000	Gwasanaethau marchnata	Gwasanaethau hysbysebu a marchnata
71420000	Gwasanaethau pensaernïaeth tirwedd	Gwasanaethau cynllunio trefol a phensaernïaeth tirlunio
71200000	Gwasanaethau pensaernïol a gwasanaethau cysylltiedig	Gwasanaethau pensaernïol, adeiladu, peirianneg ac archwilio
71240000	Gwasanaethau pensaernïol, peirianneg a chynllunio	Gwasanaethau pensaernïol a gwasanaethau cysylltiedig
71250000	Gwasanaethau pensaernïol, peirianneg ac arolygu a thirfesur	Gwasanaethau pensaernïol a gwasanaethau cysylltiedig
92620000	Gwasanaethau sy’n gysylltiedig â chwaraeon	Gwasanaethau hela
73000000	Gwasanaethau ymchwil a datblygu a gwasanaethau ymgynghori cysylltiedig	Ymchwil a Datblygu
79410000	Gwasanaethau ymgynghori ar fusnes a rheoli	Gwasanaethau ymgynghori ar fusnes a rheoli a gwasanaethau cysylltiedig
37400000	Nwyddau a chyfarpar chwaraeon	Offerynnau cerdd, nwyddau chwaraeon, gemau, teganau, crefft, deunyddiau celf ac ategolion cysylltiedig
48100000	Pecyn meddalwedd penodol i ddiwydiant	Systemau pecynnau meddalwedd a gwybodaeth
37480000	Peiriannau neu gyfarpar ar gyfer cyfarpar hamdden	Nwyddau a chyfarpar chwaraeon
30100000	Peiriannau, cyfarpar a chyflenwadau swyddfa heblaw cyfrifiaduron, argraffyddion a dodrefn	Peiriannau, cyfarpar a chyflenwadau swyddfa a busnes, heblaw dodrefn a phecynnau meddalwedd
45212140	Safleoedd hamdden	Gwaith adeiladu ar gyfer adeiladau sy’n gysylltiedig â hamdden, chwaraeon, diwylliant, tai llety a bwytai

Lleoliadau Dosbarthu

ID	Disgrifiad
1018	Abertawe
1022	Caerdydd a Bro Morgannwg
1013	Conwy a Sir Ddinbych
1015	Cymoedd Canalog (Merthyr Tudful, Rhondda Cynon Taf)
1016	Cymoedd Gwent (Torfaen, Blaenau Gwent, Caerffili)
1000	CYMRU
1014	De-orllewin Cymru (Sir Gaerfyrddin, Sir Benfro, Ceredigion)
100	DU - I gyd
1020	Dwyrain Cymru
1010	Gorllewin Cymru a'r Cymoedd
1012	Gwynedd
1017	Pen-y-bont ar Ogwr a Castell-Nedd Port Talbot
1024	Powys
1021	Sir Fynwy a Chasnewydd
1023	Sir y Fflint a Wrecsam
1011	Ynys Môn

Cyfyngiadau Rhanbarthol ar y Rhybuddion

Mae’r prynwr wedi cyfyngu’r rhybuddion ar gyfer yr hysbysiad hwn i gyflenwyr yn y rhanbarthau canlynol.

ID	Disgrifiad
Nid oes cyfyngiadau ar y rhybuddion ar gyfer yr hysbysiad hwn.

Teulu dogfennau

Manylion hysbysiad
MAY363932: Leisure Development Partner for the UK Leisure Framework 2022-2026 Dyddiad cyhoeddi: 20 Mai 2021 Math o hysbysiad: SF01 Hysbysiad Gwybodaeth Blaenorol (PIN) Enw Awdurdod: Denbighshire Leisure Ltd
JUL366128: Leisure Development Partner for the UK Leisure Framework 2022-2026 Dyddiad cyhoeddi: 13 Gorffennaf 2021 Dyddiad Cau: 12 Awst 2021 00:00 Math o hysbysiad: SF02 Hysbysiad Contract Enw Awdurdod: Denbighshire Leisure Ltd
OCT376847: Leisure Development Partner for the UK Leisure Framework 2022-2026 Dyddiad cyhoeddi: 20 Hydref 2021 Dyddiad Cau: 18 Ionawr 2022 00:00 Math o hysbysiad: Cam 2 Enw Awdurdod: Denbighshire Leisure Ltd
APR394105: Leisure Development Partner for the UK Leisure Framework 2022-2026 Dyddiad cyhoeddi: 06 Ebrill 2022 Math o hysbysiad: SF03 Hysbysiad Dyfarnu Contract - Cyflenwr(wyr) Llwyddiannus Enw Awdurdod: Denbighshire Leisure Ltd
DEC461012: Leisure Development Partner for the UK Leisure Framework 2022-2026 Dyddiad cyhoeddi: 18 Rhagfyr 2023 Math o hysbysiad: SF20 Hysbysiad Addasu Enw Awdurdod: Denbighshire Leisure Ltd

Ynglŷn â'r prynwr

Prif gyswllt:: andy.moreland@denbighshireleisure.co.uk
Cyswllt gweinyddol:: N/a
Cyswllt technegol:: N/a
Cyswllt arall:: N/a

Gwybodaeth bellach

Dyddiad	Manylion
Nid oes unrhyw wybodaeth bellach wedi'i lanlwytho.

Blwch Post

Mae'r awdurdod dyfarnu wedi nodi y bydd yn derbyn ymatebion electronig i'r hysbysiad hwn drwy'r Blwch Postio Cyflwyno Tendrau.

Cyflwyno eich ymateb i'r tendr yn electronig mewn amgylchedd diogel.

Er mwyn creu ymateb electronig, cliciwch ar y botwm "Ychwanegu at fy rhestr Diddordeb" ar frig y dudalen.

Am ragor o wybodaeth am y Blwch Postio, darllenwch y canllaw i ddefnyddwyr:

Blwch Postio Cyflwyno Tendrau ar gyfer Prynwyr a Chyflenwyr.

Cwestiynau ac Atebion

Gofyn unrhyw gwestiynau y gall fod gennych ynghylch yr hysbysiad hwn i'r prynwr. Er mwyn gofyn cwestiwn neu gwestiynau i'r prynwr cliciwch ar y botwm "Gweld Cwestiynau ac Atebion".